Work authorization form for MAXONS Restorations, Sep 2001

NYC 9/11 Public Portal Document

,reasva.o rar:3t ur(H11u1 tr+c 1j 004

Time & Materials Contrsetf*orlt Authorization Page -2-

START & COMPLETION DATES

Approximate WorK Commencement Date: • Approximate Work Completion Date:

NOTES • During the course of performance of the work, MAXONS may add additional labor and/or material classifications to the schedule above at rates to be determined by MAXONS. The Compensation Paid MAXONS for any materials utlli*ed by MAXONS in performance of the work which Ave not listed in RATE SCHEDULE above shall be twenty-flue percent (25%) MAXON$' mark-up on such costs. equal to MAXONS' cost for such services plus

• For those ltamb of equipment for which rt:ntal is expressed as a daily rate, the daily rental rate shall apply to each 24.hour period during which the equipment is in possession of MAXONS' personnel performing work regardless of the number of shifts on which such equipment is utilized during such 24-hour period. The minimum rental period for daily rental equipment is one (1) day_ • MAXONS shall be cctrnpensated for costs incurred for the transportation of equipment and the transportation beck of equipment and any remaining supplies materials to the site of the work and for and materials, Upon completion of the work, on the basis of MAXONS cost for such transportation plus twenty-five percent (25%), MAXONS mark-up thereon. • Any alteration or deviation from the above specifications will be binding only wtwn executed in writing and signed by a representative or project manager of MAXONS. • All agreements are contingent upon strikes, accidents or delays beyond our control. • Contractor will furnish Certificate of Liability Insurance end Certificate of Workers work an the contract Compensation Insurance prior to beginning the

• Contractor Wit! procure alt permits required by law

• Contractor and/or its Subcontractor may have daim against the owner. which may be enforced under New York Lien Law • Contractor is legally required to deposit all payments received prior to completion and that, instead of making these depoalts. the eontfActor may post a bond or contract the indemmnity With the owner guaranteeing the return of proper payment under the contract • Any controversy or cairn arising out of or relating to the work performed by Maxons New York under the Rules then obtaining of the American Arbitration Association. shall be settled by arbitration In the City of Matrons shall have all rights to provisional remedies, which it would have at taw or equity notwithstanding this agreement 10 arbitrate,

• In the event it becomes necessary to place this contract for collection, the undersigned accepting this contract agrees to pay all costs of collection including reasonable attorney fees and court costs.

MAXONS RESTORATIONS, INC.

License 11024157)

ACCEPTANQ@ OF CONTRACT The above specifications and conditions are satisfactory end are hereby accepted. MAXONS RESTORATIONS, INC. is authorizes to do work as specified. Pyrnenta cold be outlined above.

Accepted tfy'B'u e . ' date: __ Nonce: irou, the Buyer, nTey osn i ci/on n f t rfo to ~/dnlghr of the third business day after tea data of this frsnsaCUon

VkE:80 t0-5Z - l'O £0 - d

NYC-WTC 000094272